Terms & Conditions

Welcome to Carport King USA (“Company,” “we,” “our,” or “us”). These Terms & Conditions (“Terms”) govern your access to and use of our website, quote request forms, communications, and related services.

By using this website, submitting a quote request, contacting us, or otherwise engaging with our services, you agree to be bound by these Terms. If you do not agree, please do not use this website or our services.

1. About Our Business

Carport King USA provides information, quotes, and services related to custom metal carports, steel buildings, garages, barns, RV covers, commercial steel structures, and related products and installation services in service areas that may include Texas, Oklahoma, Arkansas, Louisiana, Georgia, and Florida.

All services are subject to availability, project requirements, location, site conditions, and applicable laws, codes, and permitting requirements.

2. Use of This Website

You agree to use this website only for lawful purposes and in a manner that does not violate any applicable law or the rights of others.

You may not:

• Use this website in any way that is fraudulent, misleading, abusive, or unlawful
• Attempt to gain unauthorized access to the website, server, forms, or connected systems
• Interfere with the website’s operation, security, or performance
• Submit false, inaccurate, or misleading information
• Copy, reproduce, republish, or exploit website content for commercial purposes without written permission

We reserve the right to suspend, restrict, or terminate access to the website at any time if we believe a user has violated these Terms.

3. Quotes, Estimates, and Pricing

Any quote, estimate, or pricing provided through the website, phone, email, form submission, or other communication is for informational purposes only unless expressly stated otherwise in a final written agreement.

Because our buildings and structures are custom, pricing may vary based on factors such as:

• Dimensions and design
• Roof style
• Wall configuration
• Material availability
• Engineering requirements
• Site conditions
• Delivery distance
• Installation complexity
• Permitting and local code requirements
• State or local compliance requirements

A quote request submitted through the website does not guarantee acceptance of a project, final pricing, delivery timeline, or installation date.

We reserve the right to correct pricing errors, typographical mistakes, inaccurate listings, or omissions at any time. Since advertising and online sales representations must be truthful and not misleading, final details should always be confirmed in the project-specific written agreement.

4. Custom Orders

Most of our products are custom-built to customer specifications. By approving a project, design, dimensions, options, or materials, you acknowledge that your order may be specially manufactured for your property and needs.

You are responsible for reviewing and confirming all order details before final approval, including:

• Structure size
• Roof style
• Color selections
• Panel and enclosure options
• Delivery location
• Site details
• Any requested upgrades or modifications

Once production, scheduling, material ordering, or installation preparation has begun, changes may be limited and may result in additional charges, delays, or cancellation restrictions.

5. Customer Responsibilities

You agree that you are responsible for providing accurate and complete information for your project.

This includes, where applicable:

• Correct contact information
• Accurate delivery and installation address
• Proper site access
• Clear project requirements
• Any homeowner association restrictions
• Any local permit or approval requirements unless otherwise agreed in writing
• Utility, drainage, or ground-condition information relevant to installation

You are also responsible for ensuring that the installation site is reasonably accessible, prepared, and suitable for the requested structure unless site preparation is expressly included in a written agreement.

6. Permits, Codes, and Compliance

We may design or provide structures intended to meet applicable local or state requirements, but permit approval, zoning, deed restrictions, inspections, and final code compliance can vary by jurisdiction and project circumstances.

Unless expressly stated in a written agreement, the customer is responsible for:

• Checking zoning restrictions
• Confirming land-use approval
• Obtaining permits
• Securing HOA approval
• Meeting local pre-installation requirements
• Ensuring the site is legally approved for the structure

Where we state that buildings are engineered for local conditions or built to applicable codes, that statement is subject to the information available for the project, jurisdiction-specific requirements, and the final approved design. Consumer-protection rules require such claims to be clear and non-deceptive, so these matters should be confirmed for each project individually.

7. Orders, Deposits, and Payments

Specific payment terms, deposit requirements, financing terms, and balance due dates, if any, will be set out in a separate quote, invoice, proposal, or written agreement.

Unless otherwise stated in writing:

• A project may require a deposit before scheduling, production, or installation
• Final payment terms may depend on the nature and size of the project
• Failure to make required payments may delay or cancel the project
• We may refuse or stop work if payment obligations are not met

All payment obligations must be satisfied according to the agreed written terms.

8. Cancellations and Refunds

Because many of our structures are custom orders, cancellations and refunds may be limited once an order is approved, materials are allocated, engineering is completed, scheduling begins, or production starts.

If a customer requests cancellation after work has begun, the customer may be responsible for costs already incurred, including but not limited to:

• Engineering or drafting
• Materials
• Administrative processing
• Delivery scheduling
• Site coordination
• Production-related costs

Any specific cancellation or refund rights will be governed by the written project agreement, quote acceptance, invoice terms, or approved order documentation.

9. Delivery and Installation Timelines

Any delivery date, installation window, or completion estimate is an estimate only unless expressly guaranteed in writing.

Project timing may be affected by:

• Weather
• Material shortages
• Manufacturing delays
• Site readiness
• Permit delays
• Access issues
• Labor scheduling
• Force majeure events
• State or local restrictions

We are not liable for delays caused by events beyond our reasonable control.

10. Warranty and Product Information

Any warranty, if offered, will be governed by the specific written terms provided with the product, manufacturer materials, installer documentation, or project agreement.

Unless expressly stated in writing, the website does not create any independent warranty beyond what is legally required or specifically included in your purchase documents.

Website descriptions, service explanations, benefits, and product references are provided for general informational purposes and may not reflect every project condition, option, or limitation.

11. No Professional Site, Engineering, or Legal Advice Through Website

Information on this website is general in nature and is not a substitute for project-specific engineering approval, site inspection, legal advice, permitting advice, survey review, or land-use approval.

You should rely on the final written agreement and any project-specific documentation for exact terms, specifications, and obligations.

12. Communications Consent

By submitting a quote request form, calling us, emailing us, or otherwise contacting us, you consent to receive communications from us regarding your request, project, pricing, scheduling, and service follow-up.

These communications may be made by phone, email, or text message, to the extent permitted by law. Standard carrier or messaging rates may apply.

If you no longer wish to receive non-essential communications, you may contact us and request that we limit those communications, except where contact is necessary to fulfill a service request or comply with legal obligations.

13. Intellectual Property

All content on this website, including but not limited to text, design, layout, graphics, branding, logos, images, icons, and written materials, is owned by Carport King USA or used with permission, unless otherwise stated.

You may not reproduce, distribute, modify, display, publish, sell, or exploit any website content without our prior written consent.

14. Third-Party Links

This website may include links to third-party websites, platforms, or social media services. Those websites operate independently and are governed by their own terms and privacy policies.

We are not responsible for the content, policies, practices, or availability of any third-party site or service.

15. Disclaimer of Warranties

This website and its content are provided on an “as is” and “as available” basis to the fullest extent permitted by law.

We make no warranties or representations, express or implied, regarding:

• The uninterrupted availability of the website
• The absence of errors, bugs, or security issues
• The completeness or accuracy of all website content at all times
• The suitability of website information for every project or jurisdiction

To the fullest extent permitted by applicable law, we disclaim all implied warranties, including implied warranties of merchantability, fitness for a particular purpose, and non-infringement, except where such disclaimers are prohibited by law.

16. Limitation of Liability

To the fullest extent permitted by law, Carport King USA and its owners, affiliates, employees, contractors, representatives, and service providers shall not be liable for any indirect, incidental, special, consequential, or punitive damages arising out of or related to:

• Use of the website
• Inability to use the website
• Reliance on website content
• Delays in communication, delivery, or installation
• Errors or omissions in website materials
• Third-party services or links

Our total liability for any claim related to website use shall not exceed the amount, if any, you paid directly to us specifically for use of the website itself, which in most cases would be zero.

Nothing in these Terms excludes liability where exclusion is not permitted by law.

17. Indemnification

You agree to defend, indemnify, and hold harmless Carport King USA and its affiliates, owners, officers, employees, contractors, and representatives from and against claims, liabilities, damages, losses, and expenses arising out of:

• Your use of the website
• Your violation of these Terms
• Your submission of false or misleading information
• Your violation of any law or third-party rights

18. Privacy

Your use of this website is also subject to our Privacy Policy, which explains how we collect, use, and protect your information.

19. Electronic Communications

By using our website or communicating with us electronically, you agree that we may communicate with you electronically where permitted by law. U.S. e-commerce law recognizes electronic records and signatures in many business contexts, subject to applicable requirements.

20. Governing Law

These Terms shall be governed by and interpreted in accordance with the laws of the applicable U.S. state governing the transaction, without regard to conflict-of-law principles, unless otherwise required by law or stated in a project-specific written agreement.

If you want a fixed version for the site, it is better to replace this clause with the exact governing state once you decide it, for example Texas or another business-home state.

21. Dispute Resolution

In the event of a dispute, both parties agree to first attempt to resolve the matter informally and in good faith.

If informal resolution is unsuccessful, disputes may be resolved in the courts of the governing state and county specified in the final written agreement or applicable law, unless arbitration or another dispute procedure is separately agreed in writing.

22. Changes to These Terms

We may update these Terms at any time. When we do, we will revise the Last Updated date at the top of this page.

Your continued use of the website after updated Terms are posted constitutes your acceptance of the revised Terms.

23. Contact Information

If you have any questions about these Terms & Conditions, please contact us:

Carport King USA
Phone: 864-280-9629
Email: bill@carportking-usa.com